Loading...
Serving Menifee, CA and surrounding areas. (951) 618-2116
Effective Date: January 1, 2026
By visiting the website at menifeesunroomsnpatios.com, contacting SunGallery Menifee Sunrooms & Patios, or entering into a service agreement with us, you agree to these Terms and Conditions. If you do not agree, please do not use our website or services. We may update these terms from time to time. The effective date at the top of this page will reflect the most recent revision.
SunGallery Menifee Sunrooms & Patios is a Sunroom Contractor based in Menifee, CA. We provide sunroom additions, patio enclosures, screen room installation, patio cover installation, and related residential construction services to homeowners in the greater Menifee area and surrounding communities.
All services are performed by or under the supervision of properly licensed personnel. The specific scope of work for any project is defined in a written contract signed by both parties before construction begins.
Free estimates are provided at no obligation. An estimate reflects the anticipated cost of a project based on information available at the time of the site visit. Estimates are not binding contracts.
Final pricing is stated in the written contract. Any changes to scope, materials, or site conditions discovered after contract signing that affect the project cost will be communicated to you in writing before additional work proceeds. We will not perform change-order work without your written or documented verbal approval.
Prices quoted in an estimate are generally valid for 30 days from the date of issue. Material costs and permit fees are subject to change.
Project start dates are established after a signed contract and required deposit are received. Start dates are estimates and may be affected by permit approval timelines, weather, material availability, or other factors outside our control. We will communicate any significant schedule changes to you promptly.
If you need to cancel or postpone a project after signing a contract, please notify us in writing as soon as possible. Cancellation terms, including any applicable fees or deposit refund policies, are specified in your individual service contract.
We reserve the right to reschedule work due to unsafe weather conditions, permit delays, or other circumstances that could affect the safety or quality of the work.
Payment terms are set out in your individual service contract. In accordance with California law, we do not require more than the lesser of ten percent of the contract price or $1,000 as a deposit before work begins on a home improvement contract.
Progress payments, if any, are tied to project milestones as described in the contract. Final payment is due upon substantial completion of the work and the passing of any required city inspections.
Accounts past due by more than 30 days from the invoice date may be subject to a late fee and/or collection proceedings. We reserve the right to place a mechanics lien on the property in accordance with California law for unpaid balances.
We stand behind our workmanship. Any specific warranty terms for labor and materials will be described in your written service contract. Manufacturer warranties on products such as windows, glass panels, and framing systems are separate from our workmanship warranty and are governed by the respective manufacturer.
Our warranty does not cover damage resulting from misuse, alterations made by others after project completion, acts of nature (including earthquakes, floods, fires, or windstorms), or normal wear and tear.
The website at menifeesunroomsnpatios.com and all information on it is provided "as is" without warranties of any kind, express or implied. We make no representations about the completeness or accuracy of general educational content on this site.
To the fullest extent permitted by applicable law, SunGallery Menifee Sunrooms & Patios shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising out of your use of our website or services. Our total liability to you for any claim arising out of a service contract shall not exceed the total amount paid by you under that contract.
Nothing in these terms limits liability that cannot be excluded under applicable law, including liability for gross negligence or willful misconduct.
All content on menifeesunroomsnpatios.com - including text, images, logos, and page layouts - is the property of SunGallery Menifee Sunrooms & Patios or its licensors. You may not reproduce, distribute, or use any content from this site without our prior written permission.
If a dispute arises between you and SunGallery Menifee Sunrooms & Patios, we encourage you to contact us directly first. Most issues can be resolved quickly through a conversation.
If a dispute cannot be resolved informally, the parties agree to attempt mediation before pursuing litigation. Any legal action arising out of these terms or a service contract shall be filed in the appropriate court in Riverside County, CA.
These Terms and Conditions and any service agreement with SunGallery Menifee Sunrooms & Patios are governed by the laws of the State of California, without regard to conflict-of-law principles. You agree to the personal jurisdiction of the courts located in Riverside County, California for any disputes that require court resolution.
We reserve the right to modify these Terms and Conditions at any time. Changes will be posted on this page with an updated effective date. Your continued use of our website or services after changes are posted constitutes acceptance of the revised terms.
Questions about these Terms and Conditions can be directed to us at:
SunGallery Menifee Sunrooms & Patios
33380 Zeiders Rd Suite 102
Menifee, CA 92584